Purpose A voluminous amount of research has been conducted on project delay in the recent past; however, the persistence of the problem demands that a relentless quest for solutions is upheld. It can be argued that the problem is likely to be more pronounced in areas where development pressure is the highest. One such area is the United Arab Emirates (UAE) where the construction industry is said to have reached an unparalleled position in the last decade. The purpose of this paper is to identify the most significant causes of delays in the UAE construction industry. Design/methodology/approach A survey was conducted targeting three key types of stakeholders, namely clients, contractors and consultants. Validity and reliability were achieved by first assessing the plausibility of construction delay variables in UAE. The verification took place after the interpretation of quantitative data, this involved presenting the findings to the main participants. The validation took place after the verification process. Rigour was achieved by engaging participants previously engaged in UAE and focussing on verification and validation, this included responsiveness of the researchers during group discussions, methodological coherence, appropriate sampling frame and data analysis. Findings From the analysis, the study unveiled a number of important causes of construction delays in the UAE, ranging from unrealistic contract durations to poor labour productivity, with consultants and clients seemingly shouldering the bulk of the “blame game”. It was evident that all the three main stakeholders in a construction project (clients, consultants and contractors) need to change their existing practices in order to ensure timely delivery of projects. The research also confirms that delays are country specific and appear to be time related hence they should be viewed within the social, economic and cultural settings of the UAE. Research limitations/implications A major limitation of the current study was the use of a single approach to facilitate data collection. Practical implications It was evident that practitioners need to change their existing practices in order to ensure timely delivery of projects. Continuous coordination and relationship between practitioners are required through the project life cycle in order to solve problems and develop project performance. Originality/value As suggested in this study methods should be put in place to reduce long and bureaucratic processes within the client’s organisations, not only to fulfil the requirements of the contract but also to suite fast-track projects.
The timely delivery of projects is one of the most important needs of clients in the construction industry and yet it still remains a highly challenging undertaking the world over. From the reviewed literature, it has been suggested that such delays usually come with and lead to far reaching consequences in the form of adversarial relationships, mistrust, litigation, arbitration, cash-flow problems, and a general feeling of trepidation towards stakeholders within the construction industry. A voluminous amount of research has been conducted on this problem in the recent past however, the persistence of the problem demands that a relentless quest for solutions is upheld. It can be argued that the problem is likely to be more pronounced in areas where development pressure is the highest. One such area is the United Arab Emirates (UAE) where the construction industry is said to have reached an unparalleled position in the last decade. Moreover, the problems of construction delays may differ from one region to another due to numerous differentiating factors. This study sought to identify the most significant causes of delays in the UAE construction industry. A survey was conducted, targeting three key types of stakeholders, namely clients, contractors and consultants. From the analysis, the study unveiled a number of important causes of construction delays in the UAE, ranging from unrealistic contract durations to poor labour productivity, with consultants and clients seemingly shouldering the bulk of the 'blame game'.
Purpose\ud In recent times, electricity as one of the most important energy sources has witnessed considerable decreases in consumption figures. These cutbacks have been mainly due to the growing increasing living standards, minimal governance and political fracture. Thus, this paper appraised the supply of electricity side in an attempt to propose a sustainable electricity framework.\ud \ud Design/methodology/approach\ud The reviewed literature identified a gap within the previous literature which had not previously been investigated, however in order to carry out the investigation a research strategy had to be formulated. Twenty semi-structured interviews were carried out with managers, engineers and electrical professionals. Prior to the commencement of the main study, a preliminary pilot study was carried out among ten senior practitioners in the General Electric Company of Libya. The purpose of the pilot study was to assess clarity of questions, timing and suitability of the respondents for the study, and to establish its reliability and validity.\ud \ud Findings\ud From the aspect of the demand the study found that there was a diverse set of factors that affect electricity demand in Libya. These included the average real price of electricity, the real value of the imported electrical appliances, GDP, population, the temperature difference and the lagged electricity demand. Secondly, from the aspect of electricity supply the study found that there was a diverse set of factors that affect electricity projects in Libya or even the development of existing projects. These factors included electricity demand, political effects, recession, oil prices and improved development of other infrastructure.\ud \ud Research limitations/implications\ud The reviewed literature identified a gap within the previous literature which had not previously been investigated, however in order to carry out the investigation a research strategy had to be formulated. Twenty semi-structured interviews were carried out with managers, engineers and electrical professionals. Prior to the commencement of the main study, a preliminary pilot study was carried out among ten senior practitioners in the General Electric Company of Libya. The purpose of the pilot study was to assess clarity of questions, timing and suitability of the respondents for the study, and to establish its reliability and validity.\ud \ud Practical implications\ud The problem confronting development of electricity projects in Libya has three components: The first is the national significance of the projects as a physical resource. The second is the conflict arising politically from within. The third is the lack of consideration given to the specific resource management issues associated with the projects within the government plans and policy statements. In addition, participants further claimed that there were three more independent factors that could affect the level of electricity demand in Libya. These were urbanisation, industrialisation and literacy rates.\ud \ud Ori...
scite is a Brooklyn-based organization that helps researchers better discover and understand research articles through Smart Citations–citations that display the context of the citation and describe whether the article provides supporting or contrasting evidence. scite is used by students and researchers from around the world and is funded in part by the National Science Foundation and the National Institute on Drug Abuse of the National Institutes of Health.
hi@scite.ai
10624 S. Eastern Ave., Ste. A-614
Henderson, NV 89052, USA
Copyright © 2024 scite LLC. All rights reserved.
Made with 💙 for researchers
Part of the Research Solutions Family.