Investigating the causes of construction delay on the perspective of organization-sectors involved in the construction industry of Bangladesh

Abstract

PurposeConstruction delay always causes massive damage to the advancing construction industries, which is no different in the case of Bangladeshi construction industries. This paper aims to investigate the major delay factors causing construction delays in public-funded, mixed and private-funded construction projects of Bangladesh. Also, it offers preventive suggestions from expert stakeholders to reduce the recurrence of delays.Design/methodology/approachAt first, an extensive literature review was conducted to identify the thirty-seven major delay factors categorized under seven groups. A questionnaire was then developed for survey at ongoing construction projects at a different division of Bangladesh. Next, data from 110 respondents were collected, and the delay factors were ranked based on the Relative Importance Index (RII); lastly, probable solutions were suggested for top-ranked delay factors based on opinions from expert stakeholders in the construction sector of Bangladesh.FindingsThe overall RII ranking of the 37 delay factors showed “Construction mistakes and defective work,” “Contract modifications by the client” and “Adverse weather condition” as the top three factors causing the delay. For public-funded projects, “Construction mistakes and defective work” and “Slow decision making by a consultant” are the top delay factors. For mixed projects, “Slow decision making of the client” and “Construction mistakes and defective work ranked top, and for private-funded projects, “Financial problems and payment delay of the client” and “Adverse weather condition” ranked top. These nuances of ranking in individual project types ascertain that the causes of delay vary in terms of project features.Practical implicationsThe outcome of this project will help identify the significant delay factors based on their severity of effectiveness associated with public-funded, mixed and private-funded projects in Bangladesh. The suggestions regarding preventing these delay factors obtained through the opinions of expert stakeholders can help reduce the effect of these delays in the context of Bangladesh and in countries where the similarity in construction environment prevails.Originality/valuePreviously, studies on construction delays in Bangladesh focused mainly on identifying the delays using qualitative analysis techniques. This study is based on a unique methodology of integrating quantitative research on delay factor identification and qualitative research on preventive measures following the opinions gathered from expert stakeholders in the construction sector.

The Moderating Effects of Statutory Laws and Regulations of Risk Factors and Management in the Kingdom of Saudi Arabia Construction Industries

“…In Bangladesh, Assafi et al (2022) used the relative importance index method and recommended that manpower, materials, consultant, contractor, contract, external and client-related factors are the key risk factors. In Nepal, Gain et al (2022) employed the relative importance index and found that the amendments in regulations, weather situations, unexpected circumstances, variation orders, productivity, functionalities, poor organizational structure, poor drafting of contracts, poor site management, financial difficulties, labor shortage, inadequate construction methods, poor decision-making, inferior quality, material shortage and drawings issues are the main hazard concerns.…”

Causes of Delay in EPC Projects: The Case of Indonesia

“…A project by [14] examined the causes of construction delays in Bangladeshi public, mixed, and privately funded building projects. The overall RII ranking of the 37 delay factors showed "Construction mistakes and defective work," "Contract modifications by the client," and "Adverse weather conditions" as the top three factors causing the delay.…”

Identifying the Causes of Delay in the Building Sector in Egypt: A Case Study of Small and Medium-Sized Companies

“…Assafi M., et al [10] investigated the perspective of construction organizations in Bangladesh about the causes of delay. The RII was the tool adopted to evaluate these causes.…”